These terms of service govern the use of the website located at https://www.jmccat.lol and the computer systems design, computer integrated systems design, and related services offered by JMC Global Cat LLC, a company operating from 12922 S Zuni Dr, Riverton - 84096-3472, United States (US). The services described on this site are developed and operated by the developer JMCCat on behalf of the company.
Please read these terms carefully before using this website or engaging the services of the studio. By accessing this website, submitting a contact form, or entering into an agreement with the company, you agree to be bound by these terms. If you do not agree with any part of these terms, do not use the website or the services. The contact email address is direct@jmccat.lol and the contact phone number is +16802505451.
1. Acceptance of Terms
By accessing the website at https://www.jmccat.lol, by submitting an inquiry through the contact form, by emailing direct@jmccat.lol, or by engaging any service of JMC Global Cat LLC, you accept these terms of service in full. The terms form a binding agreement between you and the company, and they apply to all visitors, prospective clients, and clients of the studio.
The company may update these terms from time to time, and continued use of the website or services after an update constitutes acceptance of the revised terms. If you do not agree to these terms, or to a revised version of them, you must stop using the website and the services and inform the studio of your decision.
2. Definitions
In these terms, the following words carry the meanings set out here. The company means JMC Global Cat LLC, 12922 S Zuni Dr, Riverton - 84096-3472, United States (US). The website means https://www.jmccat.lol and all of its pages. The services means the computer systems design, computer integrated systems design, integration, security, and managed operations services offered by the company.
Client means the person or organization that engages the company to perform services. Developer means JMCCat, who develops and operates the services described on this website. Content means text, images, data, software, and any other material that appears on the website or is produced during service delivery. These definitions apply throughout these terms unless the context clearly requires otherwise.
3. Description of Services
The company provides computer systems design and computer integrated systems design services within the professional, scientific, and technical services sector. These services include the design of custom computer systems, network and infrastructure architecture, integration of software platforms, cloud and data center migration, security hardening, and ongoing managed operations and support.
The exact scope of any engagement is defined in a written proposal or statement of work agreed before work begins. Information on the website about services is provided for general guidance and does not form a contractual offer. The developer JMCCat may support the delivery of services, and the company remains responsible for the quality and completion of all work delivered under an agreement.
4. Eligibility
You may use the website and the services only if you are at least eighteen years old and have the legal capacity to enter into binding agreements. By using the website or requesting services, you confirm that you meet these requirements. The services are directed to businesses, organizations, and professionals, and they are not designed for personal, household, or consumer use.
The company reserves the right to refuse service to any person or organization, to decline a proposal, or to limit the scope of work, at its discretion and without liability. If you represent an organization, you confirm that you are authorized to bind that organization to these terms, and that the organization agrees to be bound by them as well.
5. Account and Credential Responsibilities
Some services may require the use of accounts, access credentials, administrative privileges, or API keys belonging to the client. The client is responsible for maintaining the confidentiality of its own credentials and for ensuring that any credentials shared with the studio are limited to the scope necessary for the agreed work.
The client is responsible for all activity carried out under its accounts, including activity performed by its staff and contractors. The client must notify the company immediately if credentials are lost, stolen, or otherwise compromised. The studio will never ask a client for passwords through insecure channels, and clients should treat any such request as suspicious.
6. Acceptable Use
You agree to use the website and the services only for lawful purposes and in a manner consistent with these terms. You may not attempt to interfere with the operation of the website, to access areas of the infrastructure that are not publicly available, to probe for vulnerabilities, or to use automated tools in a way that disrupts normal use.
You may not use the services to deploy, host, or support content that is unlawful, harmful, defamatory, or infringing, and you may not use the services to send unsolicited messages or malware. The company reserves the right to suspend access to the website or services if a violation of this clause is identified, pending investigation.
7. Intellectual Property
All content on the website, including text, graphics, logos, and code, is the property of JMC Global Cat LLC, the developer JMCCat, or their licensors, and is protected by applicable intellectual property laws. You may view and print portions of the website for your own internal business purposes, but you may not republish, distribute, or copy the content for commercial use without written permission.
Deliverables created specifically for a client, such as configuration documentation, architecture designs, and custom code written for that client, are owned by the client once full payment is received, except where a separate agreement states otherwise. General tools, frameworks, and methodology developed by the studio remain the property of the company and are licensed to the client only as needed to use the deliverables.
8. Client Obligations
The successful delivery of services depends on active participation from the client. The client must provide accurate information, reasonable access to systems and personnel, timely responses to questions, and the decisions and approvals needed to keep a project moving. Delays in providing this support may affect delivery timelines.
The client must ensure that it has the legal right to grant the studio access to the systems, data, and facilities involved in the work, and that any data shared with the studio is collected and used in line with applicable law. The client is responsible for backing up its own data before the studio performs changes to production systems.
9. Fees, Quotes, and Payment
Fees for services are described in the proposal or statement of work provided for each engagement. Quotes are valid for the period stated in the quote, and fees may change if the scope of work changes materially or if the client requests work outside the agreed scope. Additional work is quoted separately and requires client approval.
Invoices are payable within the terms stated on the invoice, typically within thirty days of the invoice date. The company may suspend work or withhold deliverables if an invoice remains unpaid beyond the due date. Late payments may incur interest at the rate permitted by law, and the client is responsible for all reasonable costs the company incurs in collecting amounts owed.
10. Deliverables and Timelines
Timelines set out in proposals are estimates based on the information available at the time. The company will make reasonable efforts to meet agreed schedules, but timelines may be adjusted when the client changes requirements, when third parties cause delays, or when unforeseen technical issues arise during the work.
Deliverables are considered accepted unless the client raises a written concern within fourteen days of delivery. Acceptance of a deliverable confirms that it meets the agreed requirements. Any request for changes after acceptance is treated as a change to scope and is quoted and scheduled separately.
11. Warranties and Disclaimers
The company warrants that services will be performed with reasonable care, skill, and professionalism consistent with industry standards, and that deliverables will conform to the requirements set out in the agreement. If a deliverable fails to conform, the company will correct it within a reasonable time at no additional charge.
Except for the warranties set out above, the services and website are provided on an as is and as available basis, and the company makes no other warranties, whether express or implied. This includes any implied warranty of merchantability, fitness for a particular purpose, or non-infringement, to the fullest extent permitted by applicable law.
12. Limitation of Liability
To the maximum extent permitted by law, the company and the developer JMCCat will not be liable for any indirect, incidental, special, consequential, or punitive damages, including lost profits, lost revenue, lost data, or interruption of business, arising out of the use of the website or the delivery of services, even if the company has been advised of the possibility of such damages.
The total liability of the company for all claims arising out of or relating to the services, whether in contract, tort, or otherwise, is limited to the amount paid by the client for the specific services giving rise to the claim during the twelve months before the claim arose. This limitation does not apply to liability that cannot be limited by law, such as liability for death, personal injury, or fraud.
13. Indemnification
The client agrees to indemnify and hold harmless JMC Global Cat LLC, its officers, employees, contractors, and the developer JMCCat from and against any claims, damages, losses, and expenses, including reasonable legal fees, arising out of the client use of the website or services, the client violation of these terms, or the client violation of any rights of a third party.
This indemnity covers matters such as claims related to data the client provides, content the client asks the studio to host or integrate, and the client use of credentials or access granted for the work. The indemnity does not apply to liability that results from the company own negligence or willful misconduct.
14. Confidentiality
During an engagement, each party may receive information about the other party that is confidential, including technical details, financial terms, business plans, and system documentation. The receiving party will keep such information confidential and will use it only for the purpose of the engagement, disclosing it only to staff and contractors who need it to perform the work.
Confidential information does not include information that is publicly available, information independently developed without access to the confidential material, or information that must be disclosed to comply with law. The obligations of confidentiality continue during the engagement and for a reasonable period after it ends, typically five years, except for trade secrets which are protected for as long as they remain secret.
15. Termination
Either party may terminate an engagement by written notice if the other party commits a material breach of the agreement and fails to remedy that breach within thirty days of receiving notice. The company may also suspend or terminate an engagement immediately if the client fails to pay amounts due or acts in a way that endangers systems, data, or personnel.
Upon termination, the client must pay for all work completed and all costs incurred up to the date of termination. The company will return client data in its possession within a reasonable time, and provisions of these terms that are intended to survive termination, including confidentiality, limitation of liability, indemnification, and governing law, will remain in effect.
16. Governing Law
These terms and any agreements entered into under them are governed by and interpreted in accordance with the laws of the State of Utah, United States (US), without regard to its conflict of law principles. The parties agree that the courts located in the State of Utah will have exclusive jurisdiction over any dispute arising out of these terms, subject to the arbitration clause below.
The company operates from 12922 S Zuni Dr, Riverton - 84096-3472, United States (US), and this choice of law reflects the location of the studio and the delivery of its services. If any provision of these terms is held to be invalid or unenforceable under applicable law, the remaining provisions will continue in full force and effect.
17. Dispute Resolution
Before commencing any legal action, the parties will attempt in good faith to resolve any dispute arising out of these terms or the services through direct negotiation. Either party may request a meeting, and the parties will use reasonable efforts to reach a mutually acceptable resolution within thirty days.
If the dispute is not resolved through negotiation, it will be resolved by binding arbitration administered in the State of Utah, in accordance with the rules then in effect, and judgment on the award rendered by the arbitrator may be entered in any court of competent jurisdiction. Each party will bear its own costs in any such proceeding, unless the arbitrator awards costs under the applicable rules.
18. Entire Agreement
These terms, together with any proposal, statement of work, or written agreement signed by the parties, constitute the entire agreement between the parties regarding the website and the services, and they supersede all prior discussions, representations, and agreements, whether written or oral.
Any waiver of a provision of these terms must be made in writing and signed by the party granting the waiver, and a waiver of one provision will not operate as a waiver of any other provision. No term of these terms is enforceable against the company by a person who is not a party to an agreement with the company.
19. Changes to These Terms
The company may revise these terms of service from time to time to reflect changes in its services, in applicable law, or in its business practices. When the terms are revised, the last updated date at the top of this page will be changed, and the revised terms will be posted on this website.
Material changes will be announced where practical, such as through a notice on the website or a direct message to clients whose work is affected. Continued use of the website or services after a revision takes effect indicates acceptance of the revised terms. We encourage visitors and clients to review these terms periodically.
20. Contact Information
If you have questions about these terms or about an agreement with the company, contact the studio by email at direct@jmccat.lol or by telephone at +16802505451. You may also write to JMC Global Cat LLC, 12922 S Zuni Dr, Riverton - 84096-3472, United States (US). The developer JMCCat and the company team will respond as quickly as possible.
When contacting the studio about a legal matter, please include your name, the nature of the question, and any relevant reference numbers so that the team can respond accurately. The company aims to acknowledge correspondence within two business days and to provide a substantive reply within a reasonable time.